type: legislation

jurisdiction: UK

text:
Citation, commencement and extent
1
1
This Order may be cited as the Channel Tunnel (Safety) Order 2007 and comes into force on the date on which the Regulation comes into force in accordance with article 77 of the Regulation. That date will be notified in the London, Edinburgh and Belfast Gazettes.
2
Subject to paragraph (3), this Order does not extend to Northern Ireland.
3
The following articles of this Order extend to Northern Ireland —
a
article 3 in so far as it relates to article 75 of the Regulation; and
b
article 9.
Interpretation
2
In this Order —
“the 1974 Act ” means the Health and Safety at Work etc. Act 1974 ;
“the Fixed Link” means the Channel fixed link as defined in Article 1(2) of the Treaty ;
“the Intergovernmental Commission ” means the Commission established under Article 10 of the Treaty to supervise, in the name and on behalf of the Government of the United Kingdom of Great Britain and Northern Ireland and the Government of the French Republic, all matters concerning the construction and operation of the Fixed Link;
“railway undertaking” has the same meaning as in article 1xx of the Regulation;
“Regulation” means the provisions set out in the Schedule (being a regulation drawn up by the Intergovernmental Commission, under Article 10(3) (e) of the Treaty, on the safety of the Fixed Link); and
“the Treaty” means the Treaty between the United Kingdom of Great Britain and Northern Ireland and the French Republic concerning the construction and operation by private concessionaires of the Fixed Link signed at Canterbury on 12th February 1986 .
Regulation has the force of law
3
The Regulation has the force of law.
Enforcement of the Regulation
4
1
Subject to paragraphs (5) and (6), it is the duty of the Office of Rail Regulation to make adequate arrangements for the enforcement of the Regulation.
2
Subject to paragraphs (4) to (6), the provisions of the 1974 Act specified in paragraph (3) (the “specified provisions”) apply for the purposes of the enforcement of the Regulation as if in the specified provisions —
a
a reference to the “enforcing authority” was a reference to the Office of Rail Regulation;
b
a reference to the “relevant statutory provisions” was a reference to the Regulation and to the specified provisions; and
c
a reference to “health and safety regulations” was a reference to the Regulation.
3
The provisions of the 1974 Act referred to in paragraph (2) are —
a
sections 19 and 20 (appointment and powers of inspectors) , excluding section 20 (3);
b
sections 21 and 22 (improvement and prohibition notices) ;
c
section 23 (provisions supplementary to sections 21 and 22) , excluding section 23(6);
d
section 24 (appeal against improvement or prohibition notice) ;
e
section 25 (power to deal with cause of imminent danger);
f
section 26 (power to indemnify inspectors);
g
section 28 (restrictions on disclosure of information) ;
h
sections 33 (1) (c), (e) to (h), (k) to (o), (2), (2A) and (3), 34 (1) (c) and (d) and (2) to (5), 35, 36 (1) and (2), 37 to 41 and 42 (1) to (3) (provisions as to offences) ; and
i
section 46 (service of notices).
4
For the purposes of the enforcement of the Regulation section 33(1)(c) of the 1974 Act (offences) only applies to contraventions of —
a
articles 13 iv, 15 iv, 16, 22 to 25, 27, 34 (a) and (b), 39, 51, 52 (a) and (b) and 61 of the Regulation; and
b
any requirement or prohibition to which a person is subject by virtue of the terms of or any condition or restriction attached to any —
i
authorisation of rolling stock;
ii
safety authorisation; or
iii
Part B certificate;
given under the Regulation, including any deemed authorisation or Part B certificate referred to in articles 66, 73 or 74 of the Regulation.
5
Paragraphs (1) and (2) do not apply in respect of the following articles of the Regulation —
a
articles 6 and 7 (safety authority);
b
articles 56 to 60 (access to training facilities); and
c
articles 67 to 72 (investigations into accidents and incidents).
6
Paragraphs (1) and (2) do not apply for the purpose of enforcing the obligations of the Intergovernmental Commission under the Regulation.
Access to training facilities
5
1
Any railway undertaking whose train drivers or staff performing vital safety tasks are denied the entitlements conferred by articles 56, 57(a) and 58 of the Regulation has a right of appeal to the Office of Rail Regulation.
2
In relation to training services to which article 59 of the Regulation applies, a railway undertaking which considers that the price charged for access to those services is unreasonable or discriminatory has a right of appeal to the Office of Rail Regulation.
3
A person who is denied any entitlement conferred on him by article 60 of the Regulation has a right of appeal to the Office of Rail Regulation.
4
The provisions of regulation 5(3) to (5) of the Railways (Access to Training Services) Regulations 2006 (appeal to the regulatory body) apply to any appeal made under this article as if reference to an appeal in those provisions included reference to an appeal under this article.
Civil liability
6
1
Breach of a duty requirement or prohibition imposed by articles 13 iv, 15 iv, 22 to 25, 27, 34 (a) and (b), 39, 51, 52 (a) and (b) and 61 of the Regulation is, so far as it causes damage, actionable.
2
Subject to paragraphs (1) and (3) and to article 5 of this Order, nothing in this Order is to be construed as conferring a right of action in any civil proceedings in respect of any failure to comply with any duty requirement or prohibition imposed by the Regulation.
3
Paragraph (2) is without prejudice to any right to apply for judicial review which an aggrieved person may have under article 76 of the Regulation.
4
Paragraphs (1) and (2) are without prejudice to any right of action which exists apart from the provisions of this Order.
5
Any term of an agreement which purports to exclude or restrict the operation of paragraph (1), or any liability arising by virtue of that paragraph, is void.
6
In this article “damage” includes the death of, or injury to, any person (including any disease and any impairment of a person’s physical or mental condition).
Investigations into accidents and incidents
7
Nothing in this Order or the Regulation prejudices or affects the provisions of Part 1 of the Railways and Transport Safety Act 2003 or the Railways (Accident Investigation and Reporting) Regulations 2005 .
Power to impose charges
8
The Intergovernmental Commission may impose charges reflecting their administrative costs of processing applications for the following —
a
Part B certificates as required by article 39(ii) of the Regulation, including their renewal under article 50 or modification under article 52 of the Regulation, and
b
authorisation under article 61 of the Regulation for operating rolling stock on the Fixed Link.
Amendments to the Channel Tunnel (International Arrangements) Order 2005
9
1
The Channel Tunnel (International Arrangements) Order 2005 is amended as follows.
2
In the Schedule (International Articles) —
a
in Article 6 (exercise of access or transit rights) for paragraph (c) substitute —
c
has received and continues to hold a safety certificate as required by article 39 of the Regulation of the Intergovernmental Commission transposing Directive 2004/49/ EC of the European Parliament and of the Council (the Railway Safety Directive) signed on 24th January 2007;
; and
b
in Article 12 (regulatory body) for sub-paragraph (1) (f) substitute —
f
arrangements for access to the network.
.
Amendment to the Railways and Other Guided Transport Systems (Safety) Regulations 2006
10
For paragraph 1 (b) (i) of Schedule 2 to the Railways and Other Guided Transport Systems (Safety) Regulations 2006 (application for a safety certificate) substitute —
i
a copy of a current certificate issued to the applicant by —
aa
the Office of Rail Regulation, other than a deemed safety certificate;
bb
a safety authority in another member State;
cc
a safety authority in Northern Ireland; or
dd
the safety authority for the tunnel system within the meaning of section 1(7) of the Channel Tunnel Act 1987 ,
under provisions giving effect to article 10(2)(a) of the Directive which relates to an equivalent railway operation; or
.
Signed by authority of the Secretary of State for Transport
Tom Harris
Parliamentary Under Secretary of State
Department for Transport
13th December 2007


text:
Citation and interpretation
1
1
This Order may be cited as the Childcare Act 2006 (Commencement No. 2 and Savings and Transitional Provisions) Order 2007.
2
In this Order —
“ the Act ” means the Childcare Act 2006,
“the 1989 Act ” means the Children Act 1989 .
Provision of the Act coming into force on 30th March 2007
2
Section 99 of the Act (provision of information about young children: England) comes into force on 30th March 2007, in so far as it is not already in force.
Provisions of the Act coming into force on 1st April 2007
3
The following provisions of the Act come into force on 1st April 2007 —
section 11 (duty to assess childcare provision), in so far as it is not already in force,
section 15 (powers of Secretary of State to secure proper performance etc. ),
section 16 (amendments of Children Act 2004),
in relation to England, paragraph 31 of Schedule 2 (and section 103(1) in so far as it relates to that paragraph),
section 103(2) to the extent that it relates to the provisions of Schedule 3 specified below —
in Schedule 3 the repeal —
in relation to England, of section 118A of the School Standards and Framework Act 1998 ,
in relation to England, of section 149(1) of the Education Act 2002 ,
in sections 18 and 23 of the Children Act 2004 , the words there specified.
Provisions of the Act coming into force on 6th April 2007
4
The following provisions of the Act come into force on 6th April 2007 —
section 32 (maintenance of the two childcare registers), in so far as it requires the Chief Inspector to maintain the second Part of the second register (Part B of the general childcare register),
section 62 (applications for registration on the general register: childminders), except subsection (1)(b), in so far as it is not already in force,
section 63 (applications for registration on the general register: other childcare providers), except subsection (1)(b), in so far as it is not already in force,
section 64 (entry on the register and certificates), in so far as it is not already in force,
section 66 (conditions on registration),
section 67 (regulations governing activities), in so far as it is not already in force,
section 68 (cancellation of registration),
section 69 (suspension of registration), in so far as it is not already in force,
section 70 (voluntary removal from register),
section 72 (protection of children in an emergency),
section 73 (procedure for taking certain steps),
section 74 (appeals), in so far as it is not already in force,
section 77 (powers of entry) ,
section 78 (requirement for consent to entry),
section 79 (power of constable to assist in exercise of powers of entry) ,
section 82 (supply of information to Chief Inspector),
section 83 (supply of information to HMRC and local authorities), in so far as it is not already in force,
section 84 (disclosure of information for certain purposes), in so far as it is not already in force,
section 85 (offence of making false or misleading statement),
section 86 (time limit for proceedings),
section 87 (offences by bodies corporate),
section 88 (unincorporated associations),
section 90 (cases where consent to disclosure withheld), in so far as it is not already in force,
section 91 (co-operation between authorities),
section 93 (notices),
section 94 (power to amend Part 3: applications in respect of multiple premises),
section 96 (meaning of early years and later years provision etc.), in so far as it is not already in force,
section 97 (employees not to be regarded as providing childcare),
paragraphs 2, 3, 19, 29(a), 37, 38, 39, 40 and 43 of Schedule 2 (and section 103(1) in so far as it relates to those paragraphs),
section 103(2) to the extent that it relates to the provision of Schedule 3 specified below —
in Schedule 3 the repeal in section 9(2) of the Protection of Children Act 1999 of the word “or” there specified.
Provision of the Act coming into force on 1st May 2007
5
Section 12 of the Act (duty to provide information, advice and assistance) comes into force on 1st May 2007, in so far as it requires an English local authority to establish and maintain a service providing information relating to the provision of childcare in the area of the local authority by persons registered under Chapter 4 (voluntary registration) of Part 3 of the Act.
Savings and transitional provisions
6
The Schedule to this Order has effect for the purposes of making savings and transitional provisions in relation to the provisions to which it refers.
Beverley Hughes
Minister of State
Department for Education and Skills
22nd March 2007


text:
Title, commencement, extent and application
1
These Regulations —
a
may be cited as the Marketing of Vegetable Plant Material (England) (Amendment) Regulations 2007;
b
come into force on 1st July 2007;
c
extend to England and Wales but only apply in England.
Amendments to the Marketing of Vegetable Plant Material Regulations 1995
2
1
The Marketing of Vegetable Plant Material Regulations 1995 are amended as follows.
2
In regulation 2 (interpretation), in paragraph (1), for the definition of “Directive 92/33/ EEC ” substitute —
“Directive 92/33/EEC ” means Council Directive 92/33/EEC on the marketing of vegetable propagating and planting material other than seed;
.
3
In regulation 3 (plant material to which these Regulations apply) —
a
in paragraph (1)(a), for “Schedule 1” substitute “Annex II to Directive 92/33/EEC ”;
b
in paragraph (1)(b), for “Schedule 1” substitute “that Annex”.
4
In regulation 8 (information to accompany plant material) —
a
in paragraph (2), for “Council Directive 77/93/EEC ” substitute “Council Directive 2000/29/ EC ” ;
b
in paragraph (4), for “Schedule 1” substitute “Schedule 2”.
5
Omit Schedule 1 (genera and species to which Regulations apply).
Jeff Rooker
Minister of State
Department for Environment, Food and Rural Affairs
12th May 2007


text:
Citation, commencement and application
1
1
This Order may be cited as the Fire and Rescue Services (Appointment of Inspector) Order 2007 and shall come into force on the day after the day on which it is made.
2
This Order applies in relation to the discharge of functions by fire and rescue authorities whose areas are in England only.
Appointment of inspector
2
Sir Kenneth John Knight is appointed an inspector for the purposes of section 28(1) of the Fire and Rescue Services Act 2004.
Judith Simpson
Clerk of the Privy Council


text:
Citation and extent
1
1
This Order may be cited as the Mental Health Act (Commencement No. 2) Order 2007.
2
This Order extends to England and Wales.
Commencement
2
Section 51 of the Mental Health Act 2007 comes into force on 1 October 2007.
Signed by authority of the Lord Chancellor
Bridget Prentice
Parliamentary Under-Secretary of State
Ministry of Justice
4th September 2007


text:
PART 1
PRELIMINARY
Citation and commencement
1
This Order may be cited as the Ouseburn Barrage Order 2007 and shall come into force on 19th March 2007.
Interpretation
2
1
In this Order —
“the 1965 Act ” means the Compulsory Purchase Act 1965 ;
“the 1990 Act ” means the Port of Tyne Act 1990 ;
“the 1991 Act ” means the New Roads and Street Works Act 1991 ;
“the Applications Rules ” means the Transport and Works (Applications and Objections Procedure) (England and Wales) Rules 2000;
“the authorised works” means the scheduled works and any other works authorised by this Order;
“the book of reference” means the book of reference prepared in accordance with rule 12(7) of the Applications Rules and certified by the Secretary of State as the book of reference for the purposes of this Order;
“building” includes structure or any other erection or any part of a building, structure or erection;
“ the Council ” means the Council of the City of Newcastle upon Tyne;
“enactment” means any enactment, whether public, general or local and includes any order, byelaw, rule, regulation, direction, scheme or other instrument having effect by virtue of an enactment;
“the Glasshouse Bridge ” means the bridge over the Ouseburn carrying the A186 City Road (which is also known as Glasshouse Bridge) from National Grid reference point 426351, 564198 in the west to its junction with Walker Road at National Grid reference point 426501, 564199 in the east;
“highway” and “highway authority” have the same meanings as in the Highways Act 1980 ;
“the land plan” means the plan prepared in accordance with rule 12(5) of the Applications Rules and certified by the Secretary of State as the land plan for the purposes of this Order;
“the level of high water” means the level of mean high water springs;
“the limits of deviation” means the lateral limits of deviation for the scheduled works shown on the works plans and the land plan;
“the limits of land to be acquired or used” means the limits of land to be acquired or used shown on the works plans and the land plan;
“the lock gates” means all or any of the movable gates or the movable gates support beam forming part of the scheduled works;
“the Low Level Bridge ” means the bridge over the Ouseburn which is part of the unclassified highway known as Quayside from National Grid reference point 426435, 564163 in the west to National Grid reference point 426457, 564152 in the east;
“maintain” includes inspect, repair, adjust, alter, remove, reconstruct and replace and “maintenance” shall be construed accordingly;
“ Northumbrian Water ” means Northumbrian Water Limited;
“ the Ouseburn ” means the Ouseburn from its confluence with the River Tyne at National Grid reference point 426469 564068 to the Ouseburn Culvert at National Grid reference point 426168 564695, and includes the bed, banks and foreshore of the Ouseburn;
“owner”, in relation to land, has the same meaning as in the Acquisition of Land Act 1981 ;
“the planning Act ” means the Town and Country Planning Act 1990 ;
“the Port Authority ” means the Port of Tyne Authority;
“the Port Health Authority ” means the Tyne Port Health Authority;
“the River Tyne ” means the River Tyne and its tributaries, but excludes the Ouseburn;
“the scheduled works” means the works specified in Schedule 1 (description of the scheduled works) or any part of them;
“scouring” includes disturbance or collapse of the foreshore or bed of the Ouseburn;
“the sections” means the sections prepared in accordance with rule 12(3) of the Applications Rules and certified by the Secretary of State as the sections for the purposes of this Order;
“street” includes part of a street;
“street authority”, in relation to a street, has the same meaning as in Part 3 of the 1991 Act;
“tidal work” means so much of any work authorised by this Order as is in, on, under or over tidal waters or tidal lands below the level of high water;
“ the tribunal ” means the Lands Tribunal;
“ Trinity House ” means the Corporation of Trinity House of Deptford Strond;
“upstream Ouseburn” means that part of the Ouseburn lying between an imaginary line drawn across the upstream face of the Low Level Bridge and the Ouseburn Culvert at reference point 426168 564695;
“vessel” means every description of vessel with or without means of propulsion of any kind and includes anything constructed or used to carry persons, goods, plant or machinery, or to be propelled or moved, on or by water, a seaplane on or in the water and a hovercraft within the meaning of the Hovercraft Act 1968 ;
“watercourse” includes all rivers, streams, ditches, cuts, culverts, dykes, sluices, sewers and passages through which water flows except a public sewer or drain but does not include the River Tyne; and
“the works plans” means the plans prepared in accordance with rule 12(1)(a) of the Applications Rules and certified by the Secretary of State as the works plans for the purpose of this Order.
2
References in this Order to reference points shall be construed as references to Ordnance Survey National Grid Reference points.
3
With the exception of the level of the crest of the weir as provided in article 4(2)(d), all directions, distances and reference points stated in any description of works, powers or lands shall be construed as if the words “or thereabouts” were inserted after such direction, distance and reference point.
4
References in this Order to rights over land include references to rights to do, or to place and maintain, anything in, on or under land or in the air-space over its surface and references to the subsoil of any land include references to any cellar, basement, vault, arch or other construction forming part of any such land.
PART 2
WORKS PROVISIONS
Principal powers
Power to construct works and survey
3
1
The Council may construct and maintain the scheduled works.
2
Subject to article 4 (power to deviate), the scheduled works may only be constructed in the lines or situations shown on the works plans and in accordance with the levels shown on the sections.
3
The Council may, within the limits of deviation, carry out and maintain such works for the benefit or protection of maritime traffic as may be necessary or expedient for the purposes of, or for purposes ancillary to, the construction of the scheduled works.
4
Subject to paragraph (5), the Council may carry out and maintain such of the following works as may be necessary or expedient for the purposes of, or for purposes ancillary to, the construction of the scheduled works, namely —
a
works to alter the position of apparatus, including mains, sewers, drains and cables;
b
landscaping and other works to mitigate any adverse effects of the construction, maintenance or operation of the scheduled works;
c
works for the benefit or protection of premises affected by the scheduled works; and
d
monitoring and surveying the Ouseburn.
5
Without prejudice to the generality of paragraph (4), within the limits of deviation or on any land to be acquired or used by the Council for the purposes of this Order the Council may, for the purposes of, and for purposes ancillary to, the construction or maintenance of the authorised works —
a
make junctions and communications between any of those works and any watercourses and any existing streets, roads, ways, river walls, bridges and footpaths;
b
make, provide and maintain all necessary or convenient —
i
buildings, walls, banks, embankments, slipways, pavings, yards, moorings;
ii
rollers and other facilities for transporting boats; and
iii
piling, fences, culverts, drains, intakes, syphons, watercourses, weirs, sluices, wharves, mattresses, pitching, gabions, roads, bridges, paths, mains, pipes, cables, wires, machinery works and appliances.
6
Section 9 of the Salmon and Freshwater Fisheries Act 1975 shall not apply to the construction of the authorised works or to the alteration thereof.
7
On the completion of any part of the works authorised by this article the Council shall remove all temporary works placed by it in exercise of the powers conferred by this article.
Power to deviate
4
1
Subject to paragraph (3), in constructing or maintaining any of the scheduled works the Council may deviate laterally from the lines or situations shown on the works plans to any extent within the limits of deviation and may deviate vertically from the levels shown on the sections to any extent upwards or downwards.
2
The scheduled works shall be so constructed that —
a
the unobstructed opening between the walls of the lock, as shown on the works plans and sections, is not less than 5 metres wide;
b
the headroom for vessels passing through the lock is not less than 5 metres above the crest level of the weir as specified in sub-paragraph (d);
c
the cills at each end of the lock are set at 1.5 metres below Ordnance Datum (Newlyn) or at such other level as may be agreed between the Council and the Port Authority to be the level of the bed of the Ouseburn at that point immediately before the construction of the scheduled works is commenced;
d
the level of the crest of the weir, as shown on the works plans and sections, is set at 2.6 metres above Ordnance Datum (Newlyn) with a tolerance of plus or minus 10 millimetres;
e
the width of the crest of the weir, as shown on the works plans, is not less than 5 metres; and
f
they shall not interfere with the structure of the Glasshouse Bridge.
3
Nothing in paragraph (4) or paragraph (5) of article 3 (power to construct works and survey) shall authorise the Council to execute any works in contravention of the restrictions imposed by paragraph (2) of this article.
Streets
Power to execute street works
5
1
The Council may, for purposes ancillary to the authorised works, enter upon so much of any of the streets specified in columns (1) and (2) of Schedule 2 (streets subject to street works and to be temporarily stopped up) as is within the limits of land to be acquired or used and may —
a
break up or open the street, or any sewer, drain, or tunnel under it, or tunnel or bore under the street;
b
place apparatus in the street;
c
maintain apparatus in the street or change its position; and
d
execute works required for or incidental to any works referred to in sub-paragraphs (a), (b) and (c).
2
In this article, “apparatus” has the same meaning as in Part 3 of the 1991 Act.
Stopping up of streets and extinguishment of rights
6
1
Subject to the provisions of this article, the Council may, in connection with the construction of the authorised works, stop up the street specified in columns (1) and (2) of Schedule 3 (street to be stopped up) to the extent specified, by reference to the letters and numbers shown on the works plans, in column (3) of that Schedule.
2
Where a street has been stopped up under this article, all rights of way over or along the street so stopped up shall be extinguished.
3
Any person who suffers loss by the extinguishment or suspension of any private right of way under this article shall be entitled to compensation to be determined, in case of dispute, under Part 1 of the Land Compensation Act 1961 .
4
This article is subject to paragraph 2 of Schedule 5 (provisions relating to statutory undertakers etc. ).
Temporary stopping up of streets
7
1
The Council may, during and for the purpose of carrying out the authorised works, temporarily stop up, alter or divert any street specified in columns (1) and (2) of Schedule 2 (streets subject to street works and to be temporarily stopped up) to the extent specified, by reference to the letters and numbers shown on the works plans, in column (3) of that Schedule and may for any reasonable time —
a
divert the traffic from the street;
b
subject to paragraph (2), prevent all persons from passing along the street; and
c
use the stopped up parts of the street as a temporary working site.
2
The Council shall provide reasonable access for pedestrians going to or from premises abutting on a street affected by the exercise of the power conferred by this article if there would otherwise be no such access.
3
The Council shall not exercise the powers conferred by this article in relation to any street specified as mentioned in paragraph (1) without first consulting the street authority.
4
Any person who suffers loss by the suspension of any private right of way under this article shall be entitled to compensation to be determined, in case of dispute, under Part 1 of the Land Compensation Act 1961.
5
This article is subject to paragraph 2 of Schedule 5 (provisions relating to statutory undertakers etc.).
Application of the 1991 Act
8
1
The provisions of the 1991 Act mentioned in paragraph (2) and any regulations made, or code of practice issued or approved under, those provisions shall apply (with the necessary modifications) in relation to the stopping up, alteration or diversion of a street by the Council under the powers conferred by this Order where no street works are executed in that street as they would apply if the stopping up, alteration or diversion were occasioned by street works executed in that street by the Council.
2
The provisions of the 1991 Act referred to in paragraph (1) are —
section 54 (advance notice of certain works);
section 55 (notice of starting date of works);
section 59 (general duty of street authority to co-ordinate works);
section 60 (general duty of undertakers to co-operate);
section 69 (works likely to affect other apparatus in the street);
section 76 (liability for cost of temporary traffic regulation);
section 77 (liability for cost of use of alternative route); and
all such other provisions as apply for the purposes of the provisions mentioned above.
3
Sections 54 and 55 of the 1991 Act as applied by paragraph (2) shall have effect as if references in section 57 of that Act to emergency works were a reference to a stopping up, alteration or diversion (as the case may be) required in a case of emergency.
Supplementary powers and provisions
Power to dredge etc.
9
1
The Council may deepen, dredge and remove obstructions from the bed, foreshore and banks of, the Ouseburn —
a
for the purposes of the construction, operation or maintenance, of the scheduled works; or
b
for the purpose of facilitating the navigation of vessels; or
c
for the purpose of ensuring the water level upstream of the scheduled works is always higher than the level of the bed of the Ouseburn.
2
The powers conferred by this article shall only be exercisable with the prior written consent of the Port Authority, such consent not to be unreasonably withheld.
3
The Council shall pay compensation to all persons for any damage sustained by them by reason of the exercise by the Council of its powers under paragraph (1)(a) and the amount of the compensation to be paid, where not agreed, shall be determined by the tribunal.
4
The Council may use, appropriate or sell or otherwise dispose of anything (other than wreck within the meaning of Part 9 of the Merchant Shipping Act 1995 ) removed in exercise of the power conferred in paragraph (1).
Cables, pipes or wires under or over tidal water or tidal lands
10
Notwithstanding anything in this Order, any cables, pipes or wires to be laid or placed by the Council pursuant to this Order (other than those laid or placed within or attached to the structure of the scheduled works) under or over any tidal waters or tidal lands below the level of high water shall be laid or placed at such depth under, or such height over, tidal waters or tidal lands as the Port Authority and the Environment Agency may require.
Ouseburn not to be a reservoir
11
Notwithstanding the provisions of subsection (2) of section 1 of the Reservoirs Act 1975 , no part of the Ouseburn as is impounded by the scheduled works shall, by virtue of the retention of water by means of the scheduled works, be taken to be a reservoir for the purposes of that Act.
Agreements with owners of land and others for construction of works
12
1
The Council may enter into and carry into effect agreements or arrangements with the Port Authority, the Environment Agency and the owners of, or other persons interested in, any land in or through which any of the authorised works are or may be constructed, or the drainage of which may be affected by the construction of any of the authorised works, for or with respect to the doing of anything which may be necessary in order to carry out, or in consequence of, the authorised works.
2
Without prejudice to the generality of paragraph (1), any such agreement may provide for —
a
the payment by the Council of, or the making of contributions by it towards, the cost incurred, or to be incurred, by the Port Authority, the Environment Agency and any such owners or other persons in or in connection with the doing of any such thing; or
b
the payment by the Council of compensation for any injury suffered or loss incurred by the Port Authority, the Environment Agency and any such owners or other persons by reason or in consequence of the execution by the Council of the authorised works, or entry upon land.
Temporary closing of Ouseburn in connection with works
13
1
Notwithstanding anything in any other enactment or in any rule of law, the Council may temporarily close the Ouseburn between the Low Level Bridge and the Ouseburn Culvert, or any part thereof, to navigation during or for the purposes of executing any works or doing anything authorised by or under this Order.
2
The Council shall not exercise the powers conferred by paragraph (1) without the consent of the Port Authority (such consent not to be unreasonably withheld) and, in the exercise of those powers —
a
the Council shall so execute or do such works or things as to ensure that at any time no more of the Ouseburn is so closed than is reasonably necessary in all the circumstances; and
b
if it becomes necessary to close the Ouseburn completely to navigation, the Council shall use its best endeavours to secure that the minimum obstruction, delay or interference is caused to vessels which may be using or intending to use the Ouseburn and that the minimum interference is caused to persons who may be using or intending to use the Ouseburn for the purposes of trade or business.
3
Neither the Council nor the Port Authority shall be liable for any costs, damages or expenses whatsoever incurred by any person (save as provided in Part 1 of Schedule 6 (provisions for the protection of the Port Authority)) as a result, directly or indirectly, of any closure of the Ouseburn under paragraph (1).
4
In the case of an emergency, the Council’s powers under paragraph (1) may be exercised by the Council without the consent of the Port Authority provided that the Port Authority are informed of the action as soon as possible.
Diversion of flow of water
14
The Council may by means of the authorised works divert, intercept, stop up or otherwise interfere with the waters of, or the flow of water in, the Ouseburn.
Power to take, pump, impound and discharge water
15
1
The Council may take, impound and use water from, and discharge water into, the Ouseburn, and may pump any water required by it from or into the Ouseburn or pump any water found by it into the Ouseburn or into any watercourse, public sewer, or drain in connection with the construction or maintenance of the authorised works and for those purposes may lay down, take up and alter conduits, pipes and other works and conveniences and may, on any land within the limits of deviation, make openings into, and connections with, the Ouseburn, or any watercourse, public sewer or drain.
2
Any dispute arising from the exercise of the powers in paragraph (1) to connect to or use a public sewer or drain shall be determined as if it were a dispute under section 106 of the Water Industry Act 1991 .
3
The Council shall not, in exercise of the powers conferred by this article —
a
discharge any water into any public sewer or drain except with the consent (which shall not be unreasonably withheld) of the authority to which it belongs and subject to such terms and conditions as the said authority may reasonably impose;
b
make any opening into any public sewer or drain except in accordance with plans reasonably approved by and under the superintendence (if provided) of the authority to which the sewer or drain belongs; or
c
discharge any water into the Ouseburn or any other watercourse except with the consent (which shall not be unreasonably withheld) of the Port Authority or the authority to which it belongs and subject to such terms and conditions as the Port Authority may reasonably impose.
4
This article does not authorise the entry into controlled waters of any matter whose entry or discharge into controlled waters is prohibited by section 85(1), (2) or (3) of the Water Resources Act 1991 .
5
The Council shall take such steps as are reasonably practicable to secure that any water discharged into a watercourse or public sewer or drain in exercise of the powers conferred by this article is as free as may be practicable from gravel, soil or other solid substance or oil or matter in suspension.
6
In the exercise of its powers conferred by this Order the Council shall not except with the consent of Northumbrian Water (which may be given subject to such terms and conditions as Northumbrian Water may reasonably impose) move, alter or break into any public sewer, lateral drain or disposal main which is at that time vested in Northumbrian Water and shown on the sewer map maintained by Northumbrian Water in accordance with section 199 of the Water Industry Act 1991.
7
In this article —
a
“public sewer or drain” means a sewer or drain which belongs to a sewerage undertaker, the Environment Agency, an internal drainage board, a local authority, or a joint planning board; and
b
other expressions except “watercourse” used both in this article and in the Water Resources Act 1991 have the same meaning as in that Act.
Deposits in Ouseburn
16
Except so far as may be unavoidable in the construction of the authorised works, or in the exercise of the powers conferred by article 9 (power to dredge etc.) or article 15(1) (power to take, pump, impound and discharge water), the Council shall not, without the consent of the Environment Agency and Port Authority (which shall not be unreasonably withheld), deposit in or allow to fall or be washed into the Ouseburn any gravel, soil or other materials in the carrying out of the authorised works.
PART 3
PROVISIONS RELATING TO TIDAL WORKS
Tidal works not to be executed without approval of Secretary of State
17
1
A tidal work shall not be constructed, altered or replaced except in accordance with plans and sections approved by the Secretary of State and subject to any conditions and restrictions imposed by him before the work is begun.
2
If a tidal work is constructed, altered, replaced or re-laid in contravention of this article or of any condition or restriction imposed under this article —
a
the Secretary of State may by notice in writing require the Council at its own expense to remove the tidal work or any part thereof and restore the site thereof to its former condition; and if, on the expiration of a period of 30 days from the date on which the notice is served, it has failed to comply with the requirements of the notice, the Secretary of State may execute the works specified in the notice; or
b
if it appears to the Secretary of State urgently necessary so to do, he may remove the tidal work, or part of it, and restore the site to its former condition,
and any expenditure incurred by the Secretary of State in so doing shall be recoverable from the Council.
Lights on tidal works during construction
18
1
The Council shall at or near a tidal work during the whole time of the construction, alteration or replacement thereof, exhibit every night from sunset to sunrise such lights, if any, and take such other steps for the prevention of danger to navigation as the Secretary of State shall from time to time direct.
2
If the Council fails to comply with any requirement of a direction reasonably given under paragraph (1), it shall be guilty of an offence and liable on summary conviction to a fine not exceeding level 3 on the standard scale.
Provisions against danger to navigation
19
1
In the case of injury to, or destruction or decay of, a tidal work or any part thereof the Council shall as soon as reasonably practicable notify Trinity House and shall lay down such buoys, exhibit such lights and take such other steps for preventing danger to navigation as Trinity House may from time to time direct.
2
If the Council fails to notify Trinity House as required by paragraph (1) or to comply with any requirement of a direction under it, the Council shall be guilty of an offence and liable on summary conviction to a fine not exceeding level 3 on the standard scale.
Abatement of works abandoned or decayed
20
1
Where a tidal work is abandoned, or suffered to fall into decay, the Secretary of State may by notice in writing require the Council at its own expense either to repair and restore the work or any part thereof, or to remove the work and restore the site thereof to its former condition, to such an extent and within such limits as the Secretary of State thinks fit.
2
Where —
a
a work consisting partly of a tidal work and partly of works on or over land above the level of high water is abandoned or suffered to fall into decay; and
b
that part of the work on or over land above the level of high water is in such a condition as to interfere, or to cause reasonable apprehension that it may interfere, with the right of navigation or other public rights over the foreshore,
the Secretary of State may include that part of the work, or any portion thereof, in any notice under paragraph (1).
3
If, on the expiration of a period of 30 days from the date on which a notice under this article is served, the Council has failed to comply with the requirements of the notice, the Secretary of State may execute the work specified in the notice and any expenditure incurred by him in so doing shall be recoverable from the Council.
Survey of tidal works
21
If he deems it expedient, the Secretary of State may at any time order a survey and examination of a tidal work or of the site upon which it is proposed to construct the tidal work, and any expenditure reasonably incurred by him in relation to any such survey and examination shall be recoverable from the Council.
Permanent lights on tidal works
22
1
After the completion of a tidal work the Council shall at the outer extremity thereof exhibit every night from sunset to sunrise such lights, if any, and take such other steps, if any, for the prevention of danger to navigation as Trinity House may from time to time direct.
2
If the Council fails to comply in any respect with a direction reasonably given under this article, it shall be guilty of an offence and liable on summary conviction to a fine not exceeding level 3 on the standard scale.
PART 4
ACQUISITION AND POSSESSION OF LAND
Powers of acquisition
Power to acquire land
23
The Council may acquire compulsorily so much of the land shown on the land plan as land to be acquired compulsorily and described in the book of reference as may be required for the purposes of the scheduled works and may use any land so acquired for those purposes or for any other purposes that are ancillary to the scheduled works.
Application of Part 1 of Compulsory Purchase Act 1965
24
1
Part 1 of the 1965 Act, in so far as not modified by or inconsistent with the provisions of this Order, shall apply to the acquisition of land under this Order —
a
as it applies to a compulsory purchase to which the Acquisition of Land Act 1981 applies; and
a
as if this Order were a compulsory purchase order under that Act.
2
Part 1 of the 1965 Act, as so applied, shall have effect as if —
a
section 4 (which provides a time limit for compulsory purchase of land) and paragraph 3(3) of Schedule 3 (which makes provision as to the giving of bonds) were omitted; and
b
in section 11(1) (which confers power to enter on and to take possession of land subject to a notice to treat on giving not less than 14 days' notice) for the reference to 14 days' notice there were substituted:
i
in a case where the notice to treat relates only to the acquisition of subsoil or the acquisition of an easement or other right over the land, a reference to notice of one month; or
ii
in any other case, a reference to notice of 3 months.
Vesting declarations
25
1
The Compulsory Purchase (Vesting Declarations) Act 1981 shall apply as if this Order were a compulsory purchase order.
2
The Compulsory Purchase (Vesting Declarations) Act 1981, as so applied by paragraph (1), shall have effect with the following modifications.
3
In section 3 (preliminary notices), for subsection (1) there shall be substituted —
1
Before making a declaration under section 4 with respect to any land which is subject to a compulsory purchase order the acquiring authority shall include the particulars specified in subsection (3) in a notice which is —
a
given to every person with a relevant interest in the land with respect to which the declaration is to be made (other than a mortgagee who is not in possession); and
b
published in a local newspaper circulating in the area in which the land is situated.
.
4
In that section, in subsection (2), for “(1)(b)” there shall be substituted “(1)” and after “given” there shall be inserted “and published”.
5
In that section, for subsections (5) and (6) there shall be substituted —
5
For the purposes of this section, a person has a relevant interest in land if —
a
he is for the time being entitled to dispose of the fee simple of the land, whether in possession or in reversion; or
b
he holds, or is entitled to the rents and profits of, the land under a lease or agreement, the unexpired term of which exceeds one month.
.
6
In section 5 (earliest date for execution of declaration) —
a
in subsection (1), after “publication” there shall be inserted “in a local newspaper circulating in the area in which the land is situated”; and
b
subsection (2) shall be omitted.
7
In section 7 (constructive notice to treat), in subsection (1)(a), the words “(as modified by section 4 of the Acquisition of Land Act 1981)” shall be omitted.
8
References to the 1965 Act shall be construed as references to that Act as applied to the acquisition of land under article 23 (power to acquire land).
Power to acquire new rights
26
1
The Council may compulsorily acquire such easements or other rights over any land referred to in article 23 (power to acquire land) as may be required for any purpose for which that land may be acquired under that article, by creating them as well as by acquiring easements or other rights already in existence.
2
Subject to section 8 of the 1965 Act (as substituted by paragraph 5 of Schedule 4 (modification of compensation and compulsory purchase enactments for creation of new rights)), where the Council acquires a right over land under paragraph (1) the Council shall not be required to acquire a greater interest in that land.
3
Schedule 4 (modification of compensation and compulsory purchase enactments for creation of new rights) shall have effect for the purpose of modifying the enactments relating to compensation and the provisions of the 1965 Act in their application in relation to the compulsory acquisition under this article of a right over land by the creation of a new right.
Power to acquire subsoil only
27
1
The Council may compulsorily acquire so much of the subsoil of the land referred to in article 23 (power to acquire land) as may be required for any purpose for which that land may be acquired under that provision instead of acquiring the whole of the land.
2
Where the Council acquires any part of the subsoil of land under paragraph (1) it shall not be required to acquire an interest in any other part of the land.
3
Paragraph (2) shall not prevent article 30 (acquisition of part of certain properties) from applying where the Council acquires a cellar, vault, arch or other construction forming part of a house, building or manufactory.
Temporary possession of land
Temporary use of land for maintenance of works
28
1
Subject to paragraph (2), at any time during the maintenance period relating to any of the scheduled works, the undertaker may —
a
enter upon and take temporary possession of any land within the limits of land to be acquired or used if such possession is reasonably required for the purpose of maintaining the work or any ancillary works connected with it; and
b
construct such temporary works (including the provision of means of access) and buildings on the land as may be reasonably necessary for that purpose.
2
Paragraph (1) shall not authorise the Council to take temporary possession of —
a
any house or garden belonging to a house; or
b
any building (other than a house) if it is for the time being occupied.
3
Not less than 28 days before entering upon and taking temporary possession of land under this article the Council shall serve notice of the intended entry on the owners and occupiers of the land.
4
The Council may only remain in possession of land under this article for so long as may be reasonably necessary to carry out the maintenance works for which possession of the land was taken.
5
Before giving up possession of land of which temporary possession has been taken under this article, the Council shall remove all temporary works and restore the land to the reasonable satisfaction of the owners of the land.
6
The Council shall pay compensation to the owners and occupiers of land of which temporary possession is taken under this article for any loss or damage arising from the exercise in relation to the land of the powers conferred by this article.
7
Any dispute as to a person’s entitlement to compensation under paragraph (6), or as to the amount of the compensation, shall be determined by the tribunal under Part 1 of the Land Compensation Act 1961.
8
Without prejudice to article 55 (no double recovery), nothing in this article shall affect any liability to pay compensation under section 10(2) of the 1965 Act or under any other enactment in respect of loss or damage arising from the execution of any works, other than loss or damage for which compensation is payable under paragraph (6) of this article.
9
Where the Council takes possession of land under this article, it shall not be required to acquire the land or any interest in it.
10
Section 13 of the 1965 Act shall apply to the temporary use of land pursuant to this article to the same extent as it applies to the acquisition of land under this Order by virtue of article 24(1) (application of Part 1 of the Compulsory Purchase Act 1965).
11
In this article, “the maintenance period”, in relation to a scheduled work, means the period of 5 years beginning with the date on which the work is opened for use.
Compensation
Disregard of certain interests and improvements
29
1
In assessing the compensation payable to any person on the acquisition from him of any land under this Order, the tribunal shall not take into account —
a
any interest in land; or
b
any enhancement of the value of any interest in land by reason of any building erected, works executed or improvement or alteration made on relevant land,
if the tribunal is satisfied that the creation of the interest, the erection of the building, the execution of the works or the making of the improvement or alteration was not reasonably necessary and was undertaken with the intention of obtaining compensation or increased compensation.
2
In paragraph (1), “relevant land” means the land acquired from the person concerned or any other land with which that person is, or was at the time when the building was erected, the works executed or the improvement or alteration made, directly or indirectly concerned.
Supplementary
Acquisition of part of certain properties
30
1
This article shall apply instead of section 8(1) of the 1965 Act (as applied by article 24 (application of Part 1 of Compulsory Purchase Act 1965)) in any case where —
a
a notice to treat is served on a person (“the owner”) under the 1965 Act (as so applied) in respect of land forming only part of a house, building or manufactory or of land consisting of a house with a park or garden (“the land subject to the notice to treat”); and
b
a copy of this article is served on the owner with the notice to treat.
2
In such a case, the owner may, within the period of 21 days beginning with the day on which the notice was served, serve on the Council a counter-notice objecting to the sale of the land subject to the notice to treat and stating that he is willing and able to sell the whole (“the land subject to the counter-notice”).
3
If no such counter-notice is served within that period, the owner shall be required to sell the land subject to the notice to treat.
4
If such a counter-notice is served within that period, the question whether the owner shall be required to sell only the land subject to the notice to treat shall, unless the Council agrees to take the land subject to the counter-notice, be referred to the tribunal.
5
If on such a reference the tribunal determine that the land subject to the notice to treat can be taken —
a
without material detriment to the remainder of the land subject to the counter-notice; or
b
in the case of part of the land consisting of a house with a park or garden, without material detriment to the remainder of the land subject to the counter-notice and without seriously affecting the amenity and convenience of the house,
the owner shall be required to sell the land subject to the notice to treat.
6
If on such a reference the tribunal determine that only part of the land subject to the notice to treat can be taken —
a
without material detriment to the remainder of the land subject to the counter-notice; or
b
in the case of part of the land consisting of a house with a park or garden, without material detriment to the remainder of the land subject to the counter-notice and without seriously affecting the amenity and convenience of the house,
the notice to treat shall be deemed to be a notice to treat for that part.
7
If on such a reference the tribunal determine that —
a
the land subject to the notice to treat cannot be taken without material detriment to the remainder of the land subject to the counter-notice; but
b
the material detriment is confined to a part of the land subject to the counter-notice,
the notice to treat shall be deemed to be a notice to treat for the land to which the material detriment is confined in addition to the land already subject to the notice, whether or not the additional land is land which the Council is authorised to acquire compulsorily under this Order.
8
If the Council agrees to take the land subject to the counter-notice, or if the tribunal determine that —
a
none of the land subject to the notice to treat can be taken without material detriment to the remainder of the land subject to the counter-notice or, as the case may be, without material detriment to the remainder of the land subject to the counter-notice and without seriously affecting the amenity and convenience of the house, and
b
the material detriment is not confined to a part of the land subject to the counter-notice,
the notice to treat shall be deemed to be a notice to treat for the land subject to the counter-notice whether or not the whole of that land is land which the Council is authorised to acquire compulsorily under this Order.
9
In any case where by virtue of a determination by the tribunal under this article a notice to treat is deemed to be a notice to treat for less land or more land than specified in the notice, the Council may, within the period of 6 weeks beginning with the day on which the determination is made, withdraw the notice to treat; and if it does so shall pay the owner compensation for any loss or expense occasioned to him by the giving and withdrawal of the notice, to be determined in case of dispute by the tribunal.
10
Where the owner is required under this article to sell only part of a house, building or manufactory or of land consisting of a house with a park or garden, the Council shall pay him compensation for any loss sustained by him due to the severance of that part in addition to the value of the interest acquired.
Extinction or suspension of private rights of way etc. over land
31
1
All private rights of way over land subject to compulsory acquisition under this Order shall be extinguished —
a
as from the acquisition of the land by the Council, whether compulsorily or by agreement; or
b
on the date of entry on the land by the Council under section 11(1) of the 1965 Act, whichever is sooner.
2
All private rights of way over land owned by the Council which, being within the limits of land to be acquired or used shown on the land plan, are required for the purposes of this Order shall be extinguished on the appropriation of the land for any of those purposes by the Council.
3
All private rights over land of which the Council takes temporary possession under this Order shall be suspended and unenforceable for as long as the Council remains in lawful possession of the land.
4
Any person who suffers loss by the extinguishment or suspension of any private right of way under this article shall be entitled to compensation to be determined, in case of dispute, under Part 1 of the Land Compensation Act 1961.
5
This article does not apply in relation to any right of way to which section 271 or 272 of the planning Act (extinguishment of rights of statutory undertakers etc.) or paragraph 2 of Schedule 5 (provisions relating to statutory undertakers etc.) applies.
Time limit for exercise of powers of acquisition
32
After the end of the period of 5 years beginning with the day on which this Order comes into force —
a
no notice to treat shall be served under Part 1 of the 1965 Act as applied to the acquisition of land by article 24 (application of Part 1 of the Compulsory Purchase Act 1965); and
b
no declaration shall be executed under section 4 of the Compulsory Purchase (Vesting Declarations) Act 1981 as applied by article 25 (vesting declarations).
PART 5
OPERATION OF SCHEDULED WORKS ETC.
Power to operate scheduled works
33
1
The Council may operate the scheduled works and among other things may —
a
open or close the lock gates; and
b
regulate the water level in so much of the Ouseburn as is impounded by the scheduled works.
2
The power contained in paragraph (1) shall be exercised so as to safeguard and improve the environment and amenities of the Ouseburn.
3
Paragraph (2) shall not prevent the exercise of the power contained in paragraph (1) in order —
a
to prevent or alleviate any emergency;
b
to release flood water;
c
to ascertain the safest and most effective ways of using the scheduled works, to test its working or to train staff in its operation;
d
to facilitate the construction, maintenance or re-laying of any works in or beside the upstream Ouseburn; or
e
to secure and maintain satisfactory navigation in the vicinity of the scheduled works and the upstream Ouseburn.
4
When operating the scheduled works the Council shall have regard to —
a
the safety of vessels in, or passing to or from, the upstream Ouseburn or on the Ouseburn downstream of the scheduled works;
b
the requirements of vessels in, or passing to or from, the upstream Ouseburn (including the need to have freedom of access to moorings and berths in the upstream Ouseburn);
c
the desirability of developing and conserving flora and fauna in the upstream Ouseburn; and
d
any reasonable request of —
i
the Port Authority or other navigation authority for the Ouseburn for the time being for or in connection with their functions;
ii
the police or other emergency services;
iii
the Port Health Authority;
iv
the Environment Agency; and
v
Northumbrian Water.
5
The Council shall operate the scheduled works in accordance with —
a
any reasonable request of the Environment Agency or Northumbrian Water in order —
i
to protect the quality of water in the Ouseburn;
ii
to protect fish in the Ouseburn;
iii
to prevent backflow into the sewerage system; or
iv
to enable Northumbrian Water to undertake maintenance to the sewerage system;
b
any reasonable requirement of the Port Authority as to the general programme for the operation of the scheduled works in order to secure satisfactory navigation in the Ouseburn.
6
Subject to paragraph (7), notice of a request under paragraph (5)(a) —
a
shall be given in writing by a duly authorised officer of the Environment Agency or as the case may be of Northumbrian Water; and
b
shall be given as long as possible, but in any case not less than 24 hours, before the request is to be complied with.
7
a
In an emergency, upon receipt of a request from either the Environment Agency or the Port Authority to operate the scheduled works, the Council shall as soon as practicable operate the scheduled works in accordance with such request.
b
A request made pursuant to sub-paragraph (a) may be given orally by a duly authorised officer of the Environment Agency or the Port Authority but if so given it shall be confirmed in writing as soon as practicable thereafter.
8
The Council shall consult Natural England to seek their view as to ways in which the scheduled works may be operated so as to develop and conserve flora and fauna in the upstream Ouseburn.
9
The Council shall give to the Environment Agency and the Port Authority as much notice as is reasonably practicable in the circumstances of its intention to operate both lock gates simultaneously for the following purposes —
a
enabling experiments to be carried out for or in connection with the development of the most effective use of the scheduled works;
b
testing the scheduled works;
c
exercising and instructing staff in the operation and control of the scheduled works;
d
maintaining, the scheduled works, on such occasions as may be reasonably necessary, or removing the scheduled works;
e
enabling statutory undertakers to place or maintain, apparatus in, on, under or over the Ouseburn;
f
removing any debris or deposit of silt which may accumulate in the Ouseburn;
g
combating an emergency (including one where a request has been made under paragraph (7)); or
h
enabling riparian owners and others so entitled to repair walls and carry out other works in the upstream Ouseburn.
10
The Port Authority shall have regard to any notice given under paragraph (9) in exercising its powers to regulate the movement of vessels on the Ouseburn.
11
Subject as otherwise expressly provided in this Order, no liability shall arise in respect of any costs, damages, losses or expenses incurred by any person as a direct or indirect result of —
a
any obstruction to, delay of, or other interference with the passage of vessels; or
b
any change in the level of water in the upstream Ouseburn,
occasioned by the operation of the scheduled works unless the costs, damages, losses or expenses are incurred by reason of negligence in its operation.
Misuse of scheduled works, etc.
34
Any person who without lawful authority or reasonable excuse —
a
closes or opens the lock gates; or
b
in any other way interferes with the scheduled works or the operation thereof,
shall be guilty of an offence and shall for every such offence be liable on summary conviction to a fine not exceeding level 3 on the standard scale.
Navigation
Extinguishment of navigation rights etc. in upstream Ouseburn
35
1
All rights of navigation over the upstream Ouseburn whether public or private and however arising shall be extinguished to the extent that such rights are adversely affected by reason of the construction or operation of the authorised works.
2
Subject to paragraph (1), all public rights of navigation over the upstream Ouseburn are preserved and continue to be effective.
3
The Council shall pay compensation to any person who suffers damage or loss by reason of the extinguishment of rights of navigation by virtue of paragraph (1) and any question as to the amount of compensation so paid shall be determined by the tribunal.
4
In assessing any compensation payable under paragraph (3), the tribunal shall take account of —
a
the extent to which the rights mentioned in paragraph (1) have been exercised during the period of 20 years calculated retrospectively from the date of the first impoundment; and
b
the preservation of rights of navigation over the upstream Ouseburn for navigation by virtue of paragraph (2).
Navigation etc. in vicinity of scheduled works
36
1
In this article, “in the vicinity of the scheduled works” means on or in the area of water between —
a
a point 20 metres upstream (along the centre line of the navigable Ouseburn) from the northernmost point of the central pier of the scheduled works; and
b
a point 20 metres downstream (along the centre line of the navigable Ouseburn) from the southernmost point of the central pier of the scheduled works.
2
Any person who, other than in an emergency or with some other reasonable cause —
a
moors a vessel to any part of the scheduled works without the consent of the Council, except for the purpose of passing through the lock gates or under the Low Level Bridge or waiting to do so;
b
allows any vessel to drift in the vicinity of the scheduled works, except for the purpose of passing through the lock gates or waiting to do so; or
c
moors a vessel in the vicinity of the scheduled works so as to cause an obstruction to the access to or egress from the lock gates,
shall be guilty of an offence and shall be liable on summary conviction to a fine not exceeding level 3 on the standard scale.
Removal of vessels
37
1
Whenever any vessel is sunk, stranded or abandoned in the Ouseburn lying within the limits of deviation, or without lawful authority left or moored in that part of the Ouseburn, the Council may, after giving (except in an emergency) not less than 21 days' written notice to the owner of the vessel, unless it is not practicable after reasonable inquiry to ascertain the name and address of the owner, raise, remove, store or otherwise dispose of the vessel.
2
Subject to article 43 (emergency powers and consents), the power in paragraph (1) shall not be exercisable by the Council if —
a
it is within the powers of the Port Authority to deal with the vessel and the Port Authority decide to do so; and
b
if the Council, having given not less than one month’s notice to the Port Authority, is informed by the Port Authority within that time that the Port Authority intends to act and it does act within a reasonable time thereafter.
3
Where a vessel is left or moored adjoining riparian property the Council shall give not less than one month’s notice to the owner or occupier of that property and such owner or occupier may make representations to the Council as to the proposed raising, removal, storage, or disposal of the vessel.
4
Any notice given by the Council under paragraph (1) shall —
a
identify the vessel in respect of which the notice is served and its approximate location;
b
state that if the owner fails to raise and remove the vessel before the expiry of the period specified in the notice, the Council may raise and remove the vessel and recover all expenses reasonably incurred in doing so; and
c
indicate that there is a right to refer the matter to arbitration under article 38 (arbitration in respect of removal of vessels).
5
The Council may recover from the owner of any such vessel all expenses reasonably incurred by the Council in respect of the raising, removal, storage or disposal of the vessel or in raising, removing, storing or disposing of any furniture, tackle and apparel of the vessel or any goods, chattels and effects raised or removed from the vessel.
6
In any proceedings by the Council against a person served with a notice under paragraph (1) for the recovery of any expenses which the Council is entitled to recover from that person under paragraph (5), it shall not be open to that person to raise any question which could have been raised on a referral to arbitration under article 38.
7
Subject to paragraph (8), if any vessel to which paragraph (1) applies is not within 6 weeks of its removal by the Council, proved to the Council’s satisfaction to belong to any claimant, the vessel (together with any such furniture, tackle and apparel) shall vest in the Council.
8
If within 12 months of its removal a claim is made to the vessel by a person who subsequently proves to the satisfaction of the Council that he was the owner of the vessel, or has become the owner since the vessel was sunk, stranded, abandoned, left or moored as mentioned in paragraph (1), then the Council shall —
a
if the vessel is unsold, permit that person to retake it with any furniture, tackle, apparel, goods, chattels and effects on the vessel upon payment of the expenses referred to in paragraph (5); or
b
if the vessel and the furniture, tackle and apparel on the vessel have been sold, pay to that person the amount of the proceeds of such sale after deducting the said expenses, and in case such proceeds are insufficient to reimburse the Council those expenses the deficiency may be recovered from that person by the Council.
9
In this article —
“owner”, in relation to any vessel sunk, stranded, abandoned, left or moored as mentioned in paragraph (1), means the owner of the vessel at the time of its sinking, stranding, abandonment, leaving or mooring thereof; and
“vessel” includes any part of a vessel.
Arbitration in respect of removal of vessels
38
1
Any person served with a notice by the Council under article 37(1) (removal of vessels) may, within 21 days of service of the notice, serve a counter-notice on the Council disputing the notice and stating that —
a
the vessel is not sunk, stranded or abandoned in the Ouseburn lying within the limits of deviation or without lawful authority left or moored in that part of the Ouseburn; or
b
there has been some informality, defect or error in, or in connection with, the notice,
and any dispute under this article shall be determined in accordance with article 54 (arbitration).
2
If and in so far as a dispute under this article is based on the ground of some informality, defect or error in, or in connection with, the notice, the arbitrator shall dismiss the dispute if he is satisfied that the informality, defect or error was not a material one.
3
On the hearing of the dispute the arbitrator may confirm or set aside the notice.
Removal of obstructions other than vessels
39
1
This article applies to anything, other than a vessel, causing an obstruction or impediment to the navigation or use of the Ouseburn lying within the limits of deviation (in this article and article 40 referred to as an “obstruction”) and which the owner of the obstruction, or the owner or occupier of the land, as the case may be, caused or knowingly permitted to become or remain an obstruction.
2
Subject to paragraph (3), the Council may by written notice require the owner of an obstruction or, if he is not known, the owner or occupier of any land on which the obstruction is situated to mark, modify or remove the obstruction.
3
Subject to article 43 (emergency powers and consents), the power in paragraph (2) shall not be exercisable —
a
if it is within the powers of the Port Authority to deal with such obstruction and the Port Authority decide to do so; and
b
if the Council, having given not less than one month’s notice to the Port Authority, is informed by the Port Authority within that time that the Port Authority intends to act and it does act within a reasonable time thereafter.
4
If the owner of the obstruction, or the owner or occupier of the land, fails to take any action specified by the Council in a notice pursuant to paragraph (2), the Council may take that action and recover the reasonable costs of doing so from that person.
5
In any proceedings by the Council against any person required to modify, remove or mark an obstruction under paragraph (2) for the recovery of costs which the Council is entitled to recover under paragraph (4), it shall not be open to that person to raise any question which could have been raised on a referral to arbitration under article 40 (arbitration in respect of removal of obstructions other than vessels).
6
Subject to paragraph (13), the Council may —
a
mark an obstruction; or
b
modify or remove it,
in such circumstances as it considers fit.
7
Before exercising its powers under paragraph (6), the Council shall, if it is reasonably practicable to do so, give not less than 21 days' written notice of its intention to the owner or occupier of any land on which the obstruction is situated.
8
If an obstruction removed by the Council under this article is so marked as to be readily identifiable as the property of any person, the Council shall within one month of its coming into the Council’s custody give written notice, in accordance with paragraph (12), to that person and, if possession of the thing is not retaken within the period specified in, and in accordance with the terms of, the notice, it shall vest in the Council at the end of that period.
9
If an obstruction removed by the Council under this article, which is not marked as described in paragraph (8), is not within 3 months of its coming into the custody of the Council proved to the Council’s reasonable satisfaction to belong to any person, it shall vest in the Council.
10
The Council may at such time and in such manner as it thinks fit dispose of anything referred to in paragraph (9) which is of a perishable nature or the custody of which involves unreasonable expense or inconvenience notwithstanding that at the time it has not vested in the Council under this article, and if it is sold the proceeds of sale shall be applied by the Council in payment of the expenses incurred by it under this article in relation to the thing, and any balance shall —
a
be paid to any person who, within 3 months from the time when the thing came into the custody of the Council, proves to the reasonable satisfaction of the Council that he was the owner of the thing at that time; or
b
if within the said period no person proves his ownership at that time, vest in the Council.
11
If an obstruction removed by the Council under this article —
a
is sold by the Council and the proceeds of sale are insufficient to reimburse it for the amount of the expenses incurred by it in the exercise of its powers of removal; or
b
is unsaleable,
the Council may recover the deficiency or the whole of the expenses, as the case may be, from the person who was the owner at the time when the thing removed came into the custody of the Council or who was the owner at the time of its abandonment or loss, if that person caused or knowingly permitted the obstruction to be there.
12
A notice given under paragraph (8) shall specify the thing removed and state that, upon proof of ownership to the reasonable satisfaction of the Council and payment of the reasonable costs of the raising, removal and storage of the thing, possession may be retaken at the place named in the notice within the time specified in the notice, being not less than 14 days after the date when the notice is served.
13
The Council shall not under the powers of this article remove, or require the removal of, or modify, or require the modification of, any obstruction specifically authorised by any enactment or by a works licence granted by the Port Authority under section 5 of the 1990 Act.
14
In paragraph (1), reference to anything causing an obstruction or impediment to the navigation or use of the part of the Ouseburn lying within the limits of deviation is a reference to anything causing an obstruction or impediment to a vessel of a size customarily navigated or used on that part of the Ouseburn.
Arbitration in respect of removal of obstructions other than vessels
40
1
Any person required by the Council to modify, remove or mark an obstruction under article 39(2) (removal of obstructions other then vessels) may within 21 days of being so required serve a counter-notice on the Council disputing the notice on any of the following grounds which are justified by the circumstances of the particular case —
a
that the thing required to be marked, removed or modified is not an obstruction, or is specifically authorised by any enactment or by a works licence granted by the Port Authority under section 5 of the 1990 Act;
b
that the thing required to be marked, removed or modified is an obstruction which has occurred naturally and that to require its marking, removal or modification is unreasonable;
c
where the requirement is to remove the obstruction, that it would be adequate in all the circumstances of the case to mark or modify the obstruction; or
d
where the requirement is to modify the obstruction, that it would be adequate in all the circumstances of the case to mark the obstruction,
and any dispute under this article shall be determined in accordance with article 54 (arbitration).
2
Any person served with a notice under article 39(7) may within 21 days of service of the notice serve a counter-notice on the Council disputing the notice on any of the following grounds which are appropriate in the circumstances of the particular case —
a
that the thing the Council intends to mark, remove or modify is not an obstruction, or is specifically authorised by any enactment or by a works licence granted by the Port Authority under section 5 of the 1990 Act;
b
that the thing the Council intends to mark, remove or modify is an obstruction which has occurred naturally and that to mark, remove or modify it is unreasonable;
c
where the Council intends to remove the obstruction, that it would be adequate in all the circumstances of the case to mark or modify the obstruction; or
d
where the Council intends to modify the obstruction, that it would be adequate in all the circumstances of the case to mark the obstruction.
and any dispute under this article shall be determined in accordance with article 54 (arbitration).
3
On the hearing of a dispute under this article the arbitrator may confirm, vary or set aside the requirement or the notice, as the case may be.
Removal of projections
41
1
Without prejudice to article 39 (removal of obstructions other than vessels), the Council may by written notice require the owner or occupier of a projection which in the opinion of the Council is, or is likely to become, by reason of its insecure condition or want of repair —
a
dangerous to persons or vessels navigating or using the Ouseburn; or
b
a hindrance to the navigation or use of the Ouseburn,
to remedy its condition to the satisfaction of the Council within a period of time (being not less than one month) specified in the notice.
2
Any notice served by the Council under this article shall —
a
specify the works or other operations required to be carried out;
b
have annexed to it a copy of this article and of article 42 (arbitration against notices under article 41); and
c
indicate that there is a right to refer the matter to arbitration under article 42.
3
In serving a notice under this article the Council may impose such terms and conditions as it thinks fit as to how the works or other operations shall be carried out.
4
If a person required by any notice served by the Council under paragraph (1) to execute works fails to execute the works required within the time specified in the notice, the Council may itself execute the works and recover the expenses reasonably incurred by it in so doing from that person.
5
In proceedings by the Council against the person served with the notice for the recovery of any expenses which the Council is entitled to recover from that person under paragraph (4), it shall not be open to that person to raise any question which could have been raised on a referral to arbitration under article 42.
6
In this article, “projection” means anything which projects over the Ouseburn lying within the limits of deviation and includes any tree, bush or other plant but does not include any such things authorised by or under statute or by a works licence under section 5 of the 1990 Act to be placed or constructed.
Arbitration against notices under article 41
42
1
The following provisions of this article shall apply in relation to any notice served by the Council under article 41 (removal of projections).
2
A person served with such a notice may, within 21 days of service of the notice, serve a counter-notice on the Council disputing the notice on any of the following grounds which are appropriate in the circumstances of the particular case —
a
that the notice is not justified by the terms of article 41;
b
that there has been some informality, defect or error in, or in connection with, the notice;
c
that the Council has refused unreasonably to approve the execution of alternative works, or that the works required by the notice to be executed are otherwise unreasonable in character or extent, or are unnecessary;
d
that the time within which the works are to be executed is not reasonably sufficient for the purpose;
e
that the notice might lawfully have been served on the occupier of the projection in question instead of on the owner, or on the owner instead of on the occupier, and that it would have been equitable for it to have been so served; and
f
where the work is work for the common benefit of the projection in question and another projection, that the owner or occupier of the other projection to be benefited, ought to contribute towards the expenses of executing any works required,
and any dispute under this article shall be determined in accordance with article 54 (arbitration).
3
If and in so far as a dispute under this article is based on the ground of some informality, defect or error in, or in connection with, the notice, the arbitrator shall dismiss the dispute if it is satisfied that the informality, defect or error was not a material one.
4
Where the grounds upon which a dispute under this article is brought include a ground specified in paragraph (2)(e) or (f), the appellant shall serve a copy of the counter-notice on each other person referred to, and in the case of any dispute may serve a copy of the counter-notice on any other person having an estate or interest in the structure or embankment in question.
5
On the hearing of the dispute the arbitrator may confirm or set aside the notice and may make such award as he thinks fit with respect to the person by whom any work is to be executed and the contribution to be made by any other person towards the cost of the work, or as to the proportions in which any expenses which may become recoverable by the Council are to be borne by the appellant and such other person.
6
In exercising its powers under paragraph (5), the arbitrator shall have regard —
a
as between an owner and an occupier, to the terms and conditions, whether contractual or statutory, of the tenancy and to the nature of the works required; and
b
in any case, to the degree of benefit to be derived by the different persons concerned.
Emergency powers and consents
43
The Council’s powers under articles 37 (removal of vessels), 39 (removal of obstructions other than vessels) and 41 (removal of projections) may be exercised by the Council in an emergency without prior notice to the Port Authority provided that the Port Authority are informed of the action as soon as possible thereafter.
Byelaws
Byelaws
44
1
In addition to its powers to make byelaws under any other enactment, the Council may make byelaws in relation to the navigation and use of those parts of the Ouseburn which fall within the limits of deviation, and for its good management in connection with such navigation and use.
2
In particular, byelaws under paragraph (1) may be made for all or any of the following purposes —
a
for prohibiting or regulating recreational activities;
b
for regulating navigation and for the prevention of obstruction to navigation;
c
for regulating the speed and movement of vessels;
d
for securing the safety of vessels and persons using the scheduled works and of their property, and any property situated within the limits of deviation;
e
for regulating the passage of vessels, or any class of vessels, through the lock gates or over or through other structures, works or apparatus, either generally or in circumstances prescribed by the byelaws; or
f
for preventing swimming.
3
The Council shall not make any byelaws under this article without the consent of the Environment Agency, the Port Authority and the Port Health Authority.
4
The Environment Agency and the Port Health Authority shall not withhold their consent to the making of any byelaw except on the ground that it conflicts with or duplicates a byelaw of that authority; and any unresolved question whether there is any such conflict or duplication shall be determined in accordance with article 54 (arbitration).
5
Nothing in any byelaw made under this article shall apply to anything done by the Port Authority in the exercise of any of their statutory functions and the byelaws of the Port Authority shall be unaffected by any byelaw made under this article.
6
In making any byelaws under this article the Council shall take into account matters relating to public safety and any reasonable requirements of the Environment Agency, the Port Authority and the Port Health Authority.
7
Byelaws under this article may provide for it to be an offence for a person to contravene, or to fail to comply with, a provision of the byelaws and for such a person to be liable on summary conviction to a fine not exceeding level 3 on the standard scale.
8
The provisions of sections 236(3) to (8) and (11) and 238 of the Local Government Act 1972 (which relates to the procedure for making, and evidence of, byelaws) shall apply to any byelaws made by the Council under this article.
9
In its application to byelaws made under this article by the Council, section 236 of the Local Government Act 1972 shall have effect as if in subsection (7), after the word “confirm” where it first occurs, the words “with or without modification” were inserted.
10
The confirming authority for the purposes of section 236 of the Local Government Act 1972 in its application to byelaws made under this article shall be the Secretary of State.
11
The Secretary of State may charge the Council a reasonable fee for the purpose of defraying any administrative expenses incurred by him in respect of byelaws made under this article which are submitted to him for confirmation.
12
Where in relation to any byelaws submitted to him for confirmation the Secretary of State proposes to make a modification which appears to him to be substantial he shall inform the Council and require it to take any steps he considers necessary for informing persons likely to be concerned with the modification and shall not confirm the byelaws until such period has elapsed as he thinks reasonable for consideration of, and comment upon, the proposed modification by the Council and by other persons who have been informed of it.
PART 6
PROTECTIVE PROVISIONS
Protection of certain persons
45
The provisions of Schedule 5 (provisions relating to statutory undertakers etc.) and Schedule 6 (protection of certain persons) shall have effect.
Saving for Trinity House
46
Nothing in this Order shall prejudice or derogate from any of the powers, rights or privileges, or the jurisdiction or authority, of Trinity House.
Crown rights
47
1
Nothing in this Order affects prejudicially any estate, right, power, privilege or exemption of the Crown and in particular, and without prejudice to the generality of the foregoing, nothing in this Order shall authorise the Council or any other person to take, use, enter upon or in any manner interfere with any land or hereditament or any rights of whatsoever description belonging to Her Majesty in right of the Crown and under the management of the Crown Estate Commissioners without the consent in writing of those Commissioners.
2
Consent under this article may be given unconditionally or subject to such terms or conditions as shall be considered necessary or appropriate.
Minerals
48
Nothing in this Order shall affect the rights of any person entitled to any mine or minerals of any description whatsoever under a street or other land in, on, or adjacent to which the authorised works are constructed to work the mine or get the minerals but this shall not affect any liability (whether civil or criminal) of the person so entitled in respect of any damage to the authorised works resulting from the exercise of any such rights.
Access to scheduled works
49
The Council shall at all reasonable times, upon receipt on each occasion of not less than 48 hours' written notice, afford to any duly authorised representative of the Port Authority or the Environment Agency or the Port Health Authority access without payment or charge to the scheduled works or to a tidal work for the purposes of inspection and survey of the scheduled works or a tidal work in connection with the exercise of the Port Authority’s or the Environment Agency’s or the Port Health Authority’s functions and shall provide reasonable facilities for those purposes.
PART 7
MISCELLANEOUS AND GENERAL
Power to transfer undertaking
50
1
The Council may, with the consent of the Secretary of State —
a
transfer to another person (“the transferee”) its right to construct, maintain, use or operate the authorised works (or any part of them) and such related statutory rights as may be agreed between the Council and the transferee; or
b
grant to another person (“the lessee”) for a period agreed between the Council and the lessee the right to construct, maintain, use or operate the authorised works (or any part of them) and such related statutory rights as may be so agreed.
2
Where an agreement has been made by virtue of paragraph (1) references in this Order to the Council shall include references to the transferee or the lessee.
3
The exercise of the powers conferred by any enactment by any person in pursuance of any transfer or grant under paragraph (1) shall be subject to the same restrictions, liabilities and obligations as would apply under this Order if those powers were exercised by the Council.
4
Subject to paragraph (5), the Council shall not under this article transfer or lease any rights conferred by Part 5 —
a
in so far as such rights relate to the Ouseburn lying within the limits of the Port Authority as defined in the Port of Tyne Reorganisation Scheme 1967 , without the consent in writing of the Port Authority, such consent not to be unreasonably withheld; and
b
without informing the Environment Agency.
5
The Council shall not under this article transfer or lease any rights conferred by article 44 (byelaws).
Obstructing execution of Order
51
Any person who, without reasonable excuse, obstructs any person acting under the authority of the Council in setting out the lines of the scheduled works, or in constructing any authorised work or who interferes with, moves or removes any apparatus belonging to any such person shall be guilty of an offence and liable on summary conviction to a fine not exceeding level 3 on the standard scale.
Defence of due diligence
52
1
In proceedings for an offence under Part 3, it shall be a defence for the Council to prove that it took all reasonable precautions and exercised all due diligence to avoid the commission of the offence.
2
If in any case the defence provided under paragraph (1) involves the allegation that the commission of the offence was due to the act or default of another person, the Council shall not, without leave of the court, be entitled to rely on that defence unless, not less than 7 clear days before the hearing, it has served on the prosecutor a notice in writing giving such information as was then in its possession, identifying or assisting in the identification of, that other person.
Certification of plans etc.
53
The Council shall, as soon as practicable after the making of this Order, submit copies of the book of reference, the sections, the land plan and the works plans to the Secretary of State for certification that they are true copies of, respectively, the book of reference, sections and plans referred to in this Order; and a document so certified shall be admissible in any proceedings as evidence of the contents of the document of which it is a copy.
Arbitration
54
Unless otherwise provided in this Order, any difference under any provision of this Order shall be referred to and settled by a single arbitrator to be agreed between the parties or, failing agreement, to be appointed on the application of either party (after giving notice in writing to the other) by the President of the Institution of Civil Engineers.
No double recovery
55
Compensation shall not be payable in respect of the same matter both under this Order and any other enactment, any contract or any rule of law.
Service of notices
56
1
A notice or other document required or authorised to be served for the purposes of this Order may be served —
a
by post; or
b
subject to paragraphs (5), (6), (7) and (8), by electronic transmission.
2
Where the person on whom a notice or other document to be served for the purposes of this Order is a body corporate, the notice or document is duly served if it is served on the secretary or clerk of that body.
3
For the purposes of section 7 of the Interpretation Act 1978 as it applies for the purposes of this article, the proper address of any person in relation to the service on him of a notice or document under paragraph (1) is, if he has given an address for service, that address, and otherwise —
a
in the case of the secretary or clerk of a body corporate, the registered or principal office of that body; and
b
in any other case, his last known address at the time of service.
4
Where for the purposes of this Order a notice or other document is required or authorised to be served on a person as having any interest in, or as the occupier of, land and his name or address cannot be ascertained after reasonable enquiry, the notice may be served by —
a
addressing it to him by name or by the description of “owner”, or as the case may be “occupier”, of the land (describing it); and
b
either leaving it in the hands of a person who is or appears to be resident or employed on the land or leaving it conspicuously affixed to some building or object on or near the land.
5
Where a notice or other document required to be served or sent for the purposes of this Order is served or sent by electronic transmission the requirement shall be taken to be fulfilled where the recipient of the notice or other document has given his consent to the use of electronic transmission either in writing or by electronic transmission.
6
Where the recipient of a notice or other document served or sent by electronic transmission notifies the sender within 7 days of receipt that he requires a paper copy of all or any part of that notice or other document the sender shall provide such a copy as soon as reasonably practicable.
7
A person may revoke his consent to the use of electronic transmission in accordance with paragraph (8).
8
Where a person is no longer willing to accept the use of electronic transmission for any of the purposes of this Order he shall —
a
give notice in writing or by electronic transmission revoking any consent given by him for that purpose; and
b
such revocation shall be final and shall take effect on a date specified by the person in the notice but that date shall not be less than 7 days after the date on which the notice is given.
9
This article shall not be taken to exclude the employment of any method of service not expressly provided for by it.
10
In this article, “electronic transmission” means a communication transmitted —
a
by means of an electronic communications network; or
b
by other means but in electronic form.
Signed by authority of the Secretary of State
Ellis Harvey
Head of the Transport and Works Act Orders Unit,
Department for Transport
26th February 2007